CST CST Contract & Procurement Scheduling 2

Question 1

What is a 'Time Impact Analysis' (TIA) and when is it typically used?

Accepted Answer

A schedule analysis method used to evaluate the impact of a change or delay event on the project completion date

Answer

A Time Impact Analysis models the effect of a specific change event or delay by inserting its activities into the schedule at the time of impact and measuring the resulting change in project completion date.

Question 2

Under a lump sum contract, how does a contractor typically demonstrate entitlement to a time extension for owner-caused delay?

Accepted Answer

By performing a delay analysis showing the owner's delay impacted the critical path and extended the project completion date

Answer

Entitlement to a time extension under a lump sum contract requires demonstrating through schedule delay analysis that the owner-caused delay affected critical path activities and extended the project's planned completion date.

Question 3

What is the 'concurrent delay' doctrine in construction scheduling disputes?

Accepted Answer

When both the owner and contractor contribute to project delay during the same time period, which can affect each party's entitlement to time extension or delay damages

Answer

Concurrent delay occurs when owner-caused and contractor-caused delays overlap in time, and the doctrine governs how courts and arbitrators apportion time extension entitlement and delay damages between the parties.

Question 4

What scheduling document is commonly required by public agency contracts to substantiate a contractor's request for a time extension?

Accepted Answer

A contemporaneous schedule delay analysis using the accepted project schedule

Answer

Public agency contracts typically require a schedule delay analysis prepared from contemporaneous schedule data to demonstrate that the claimed delay affected the critical path and justifies a time extension.

Question 5

What is the 'contract completion date' versus the 'forecast completion date' in project scheduling?

Accepted Answer

The contract completion date is the agreed contractual deadline; the forecast completion date is the scheduler's current projection of when the project will actually finish

Answer

The contract completion date is the deadline established in the contract documents, while the forecast completion date reflects the current schedule analysis of when the project is expected to be completed based on actual progress.

(CST) Certified Scheduling Technician Practice Test

(CST) Certified Scheduling Technician Practice Test

CST CST Contract & Procurement Scheduling 2